Mustons Lane Reconstruction CH 0.00 to CH 1530.00

Overview Wellington Shire Council is seeking a contractor for the reconstruction and widening of Mustons Lane from Chainage 0.00 to Chainage 1530.00. The contractor shall supply all labour, equipment, and consumables to complete the contract. Scope The works to be performed under this contract include but may not be limited to the following: The scope includes: Reconstruction and widening to a 6.6 m wide formation with full bitumen seal from CH 0.00 to CH 1530.00 Preparation and management of a Site Management Plan, including a Quality Management Plan, a Traffic Management Plan, a Health and Safety Co-ordination Plan, and an Environmental Management Plan Local resident notification of works, including duration and contact details of the contractor's representative Site establishment Construction management and documentation during the works under contract Locating services Ensuring local resident access during the works under contract Obtaining all permits and approvals for the works under contract Clearing and grubbing that does not require a permit, and disposal of site Tree and vegetation removal in accordance with DEECA permit and Australian Standards Disposal of all spoil, waste and debris off site, including all testing, reports, approvals and disposal fees Management of traffic Set out of works Temporary works as required Testing of materials as specified and/or in accordance with manufacturers' recommendations Reinstatement of disturbed areas, including seeding of batters and road embankment Maintenance of works prior to Practical Completion Rectification of defects and omissions during the Defects Liability Period Supply of all materials and undertaking of all activities associated with the works as specified Provision of As Constructed Information, with survey information in MGA 2020, Zone 55, and AHD, in 3D Civil CAD format Instructions to Tenderers All questions, requests for further information, or requests for clarification are to be submitted via the e-tendering portal no later than 5 business days prior to the tender closing. Wellington Shire Council restricts all questions and enquiries to the respondent and its representatives. Enquiries through potential sub-contractors and suppliers must be directed through the respondent. Wellington Shire Council may restrict the period during which it will accept questions, requests for further information, or requests for clarification. Enquiries Any enquiries regarding this tender may be directed to: Project Manager: Tony Price, Telephone: 03 5142 3038, Mobile: 0437 008 544, Email: AntonyP@wellington.vic.gov.au Coordinator Projects: Mike Kareem, Telephone: 03 5142 3156, Mobile: 0437 447 612, Email: mikek@wellington.vic.gov.au