Early Contractor Involvement Contract for the Perth Children’s Hospital Neonatal Expansion Project

Overview The Department of Transport and Major Infrastructure (WA) is seeking an Early Contractor Involvement (ECI) Contractor for the Perth Children's Hospital Neonatal Expansion Project (PCHNE). The Western Australian State Government has approved funding to expand the Neonatal Care facilities at the Perth Children's Hospital site. Scope An opportunity exists for the provision of Early Contractor Involvement (ECI) services to develop a Design and Construct (D&C) Offer for the design and construction of the following: Relocation of the existing 24-bed Ward 2B into the vacated West Block office accommodation Conversion of vacated Ward 2B into a Neonatal Care Unit accommodating 19 neonatal patient beds and 2 new mother rooms to minimise mother and baby separation Expansion of the existing Newborn Emergency Transport Service to support increased patient transfers to and from the new Neonatal Care Unit Cladding remediation, which may form part of an Early Works Agreement Coordination with the State to ensure hospital operations are maintained at all times, minimising the impact of construction works on hospital operations This Request seeks Offers for the appointment of an ECI Contractor to develop a D&C Offer to undertake design and construction of the Works. Contract Terms and Conditions Site works are anticipated to commence in quarter one (Q1) of 2027 Practical completion of all Works is required by January 2029 Tender Briefing An industry briefing session for potential Respondents to receive and clarify information regarding this Request will be held, as follows: Date: 19 October 2026 Time: 10.00 AM (WST) Venue: Office of Major Infrastructure Delivery, 34-50 Stirling Street, Perth Attendance at the industry briefing session is optional. Potential Respondents are required to register their intention to attend by contacting the Senior Project Director via PCHNeonatalExpansion@omid.wa.gov.au to confirm attendance by close of business Thursday 15 October 2026. The name and organisation of all attendees will be recorded by the State. Due to potential capacity constraints, individuals registered with the State via the formal registration process will be given priority access to the industry briefing session. Enquiries Contact: Trudy Grimshaw, Senior Project Director Email: PCHNeonatalExpansion@omid.wa.gov.au